News & Events

JUN 2021 NEWS NGO-MARTINS OKONMAH

INTRODUCTION

Since the publication by the Fédération Internationale des Ingénieurs Conseils (“FIDIC”) of the 2017 Edition of the FIDIC Suite of Contracts, there have been discussions about its key features and how they differ from those of the 1999 FIDIC Suite of Contracts. Many commentators have pointed out the distinction between the notification and claims management provisions under the 1999 and 2017 FIDIC Suite of Contracts. However, these provisions have not been analysed from the perspective of the risk of Employer-caused delays. This article analyses the claims provisions in the 2017 FIDIC suites of Contracts from the perspective of the allocation and transfer of the risk of Employer- caused delays. The analysis will compare the distinct approach adopted in 1999 and 2017 FIDIC Suites of Contracts highlighting the issues, implications and proposing recommendations in relation to the way the discretionary power accorded the Engineer under sub-clause 20.2.5 of the 2017 FIDIC Form should be applied in the allocation of Employer-caused risk between the parties.

AN OVERVIEW OF THE PREVENTION PRINCIPLE

A discussion of the prevention principle is relevant because its operation or implication operates to reallocate risk and determine liability for delays resulting from Employer’s default. This Section provides an overview of the prevention principle under English law (and indeed most common law countries) and its effect on the allocation of risk of Employer-caused delay.

The “prevention principle” operates to render inapplicable a liquidated damages clause where the Employer or his agents causes completion of the works to be delayed, leaving the Employer to prove his damages at large, and the Contractor obliged only to complete the works within a reasonable time. It is founded upon the broader notion that a party cannot enforce a contractual obligation if that party has prevented the other party from complying with the obligation. Lord Denning, in Amalgamated Building Contractors Ltd v Waltham Holy Cross Urban District Council, said: “… the building owner cannot insist on a condition if it is his own fault that the condition has not been fulfilled.” Brooking J in SMK Cabinets v Hili Modern Electrics Pty Ltd described the prevention principle as being “grounded upon considerations of fairness and reasonableness”.

The prevention principle does not depend upon a breach of contract by the Employer and applies to actions by the Employer which are permitted by contract but nevertheless impedes the progress of works. It is a principle that has been applied by the courts where, for example, the Employer

(i) had failed to give possession of the site; (ii) had failed to provide plans at the proper time; (iii) had interfered improperly through its agent in the carrying out of the works; (iv) had ordered extras which necessarily delay the works; (v) had failed to deliver components it was bound to provide; or (vi) had delayed in giving essential instructions. In these cases, the Contractors were required to complete the work within a reasonable time as determined by the court as time was said to be set “at large”.

Even if the Contractor would have been unable to complete on time in the absence of an act of prevention by the Employer, the prevention principle will render the liquidated damages clause unenforceable unless any of the exceptions to the principle applies. The court will not seek to apportion delay in determining the enforceability of the liquidated damages clause. However, if the prevention occurs after the contractual completion date, when the Contractor is already in delay, the Employer will recover liquidated damages up to the date of prevention and may be able to do so.

Read more>>

This article was first published in the International Construction Law Review Volume 38, Part 2, April 2021, http://i-law.com/ilaw/construction.htm. The article citation for which is [2021] ICLR 240